Terms and Conditions
These Terms and Conditions outline the rules and regulations for using the Indo Sports Infra website and services. By accessing this website or engaging with our services, you agree to comply with and be bound by these terms. If you do not agree with any part of these terms, you should discontinue the use of our website and services.
Company Overview
Indo Sports Infra specializes in the design, development, and installation of sports infrastructure including box cricket arenas, cricket nets, cricket grounds, multi-sports turf facilities, artificial grass installations, football turfs, indoor badminton courts, pickleball courts, and other sports-related infrastructure services. Our services are delivered through professional planning, quality materials, and expert execution.
Use of the Website
The content available on this website is provided for general informational purposes about our services, projects, and company activities. Users agree not to misuse the website, attempt unauthorized access, distribute malicious software, or use the website for any unlawful activities. Any misuse may result in restricted access or legal action where necessary.
Service Requests and Project Agreements
All infrastructure development or installation services offered by Indo Sports Infra are subject to detailed discussions, site inspection, and a formal quotation or agreement. Project scope, materials, pricing, and timelines will be clearly defined in the official proposal or agreement before work begins.
Project Timelines
The duration required for construction or installation varies depending on the size and complexity of the project, site conditions, weather conditions, and material availability. While Indo Sports Infra strives to meet estimated timelines, unforeseen circumstances may occasionally affect project schedules.
Pricing and Payments
All services provided by Indo Sports Infra are subject to agreed pricing and payment schedules mentioned in the project quotation or agreement. Payments may include advance deposits, milestone payments during project execution, and final settlement upon project completion. Delays in payments may lead to delays in project progress.
Client Responsibilities
Clients are responsible for providing accurate project requirements, timely approvals, and access to the project site. Any delay in approvals, site readiness, or necessary permissions from authorities may impact the project schedule and completion timeline.
Changes and Modifications
Any design changes, additional features, or scope modifications requested after the project has started may lead to additional costs and extended timelines. All changes will be documented and approved by both parties before implementation.
Quality and Performance
Indo Sports Infra uses quality materials and professional installation practices to ensure durable and high-performance sports infrastructure. Our installations are designed to support heavy daily usage, provided that proper maintenance and responsible use are followed.
Maintenance and Support
Guidance regarding the maintenance of installed sports infrastructure may be provided after project completion. Additional maintenance, repairs, or upgrades may be offered upon request and may involve additional service charges.
Intellectual Property
All content on this website, including text, images, graphics, designs, logos, and project visuals, is the property of Indo Sports Infra unless otherwise stated. Unauthorized reproduction, copying, or distribution of this content without permission is strictly prohibited.
Third-Party Links
This website may contain links to external websites or services for informational purposes. Indo Sports Infra is not responsible for the content, privacy practices, or reliability of these third-party websites.
Limitation of Liability
While Indo Sports Infra aims to provide accurate and up-to-date information on this website, we do not guarantee that all content is free from errors or omissions. The company shall not be held responsible for any direct or indirect damages resulting from the use of this website or reliance on the information provided.
Termination of Use
Indo Sports Infra reserves the right to restrict or terminate access to the website for users who violate these Terms and Conditions or engage in activities that harm the website or business operations.
Updates to Terms and Conditions
We may update or modify these Terms and Conditions at any time without prior notice. Continued use of the website following any updates indicates acceptance of the revised terms.
Governing Law
These Terms and Conditions are governed by the laws of India. Any disputes arising from the use of this website or our services will be subject to the jurisdiction of the courts located in Telangana, India.
Contact Us
If you have any questions or concerns regarding these Terms and Conditions, please contact us using the details below.
Indo Sports Infra
Email: info@indosportsinfra.com
Phone: +91 9000791984
Address: H No. 10-6-329, Plot No. 47N, Sri Sai Nagar Colony, Lingojiguda, Hyderabad, Rangareddy, Telangana – 500035, India
We are committed to delivering reliable sports infrastructure services while maintaining transparency and professionalism in all our business practices.